Construction Contract Basics: No Damages for Delay
May 06, 2024 —
Christopher G. Hill - Construction Law MusingsAfter WAY too long a hiatus, I am back with another in my series of “Construction Contract Basics” posts. In past posts, I’ve covered venue provisions, attorney fee provisions, and indemnity clauses. In this post, I’ll share a few thoughts (or “musings”) on the topic of so-called “no damages for delay” clauses. These clauses essentially state that a subcontractor’s only remedy for a delay caused by any factor beyond its control (including the fault of the general contractor), after proper notice to the owner or general contractor, is an extension of time to complete the work.
These types of clauses generally make it impossible for a subcontractor (if found in a Subcontract) or Contractor (if found in a Prime Contract) that is delayed through no fault of its own to recover any damages relating to the expenses that are inevitably caused by such delays. Such expenses/damages could include additional supervisory time (including more high-dollar superintendent payments), acceleration costs, demobilization/mobilization costs, and other related expenses. These can add up to real money. Couple that with the inevitable liquidated damages or delay damages that will occur should a contractor or subcontractor cause any delay, and this becomes a very one-sided proposition.
Read the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
A New Lawsuit Might Change the Real Estate Industry Forever
December 23, 2023 —
Tracy Alloway, Joe Weisenthal, and Aashna Shah - BloombergLast month, a Missouri jury found that real estate brokers colluded to artificially inflate and fix their own commissions, and as a result, ordered the National Association of Realtors to pay $1.8 billion in damages. While the ruling will be appealed, with highly uncertain damages and remedies, the case is shining a light on how participants in the real estate industry get paid, and raising the question of whether homebuyers are paying too much to their brokers. So how do brokers get paid? What are their incentives? And why haven't fees for brokers gone down, even as online platforms that compete with them have proliferated. On this episode of the podcast, we speak with Andra Ghent, a finance professor at the University of Utah and a specialist in real estate who explains how the structure works currently, and how the lawsuit could ultimately change the entire business model of buying and selling homes. This transcript has been lightly edited for clarity.
Reprinted courtesy of
Tracy Alloway, Bloomberg,
Joe Weisenthal, Bloomberg and
Aashna Shah, Bloomberg Read the full story...
Don’t Fall in Trap of Buying the Cheapest Insurance Policy as it May be Bad for Your Business Risks and Needs
March 25, 2024 —
David Adelstein - Florida Construction Legal UpdatesDon’t fall in the trap of buying the cheapest insurance policy. It will come and bite you in the butt big time! Consult with an insurance broker that understands construction and, importantly, your specific industry, to provide you coverage within your industry. Otherwise, you’ll be paying for a policy that may (i) not be a good policy, and (ii) may provide you minimal to no value for your industry’s RISKS and NEEDS when factoring in exclusions. When procuring insurance, think of the old adage “penny wise and pound foolish,” and don’t make decisions that fit within this adage!
The recent decision in Nautilus Ins. Co. v. Pinnacle Engineering & Development, Inc., 2024 WL 940527 (S.D. Fla. 2024) serves as an example. Here, a subcontractor was hired by a general contractor to perform underground utility work for a townhome development which consisted of 57 townhome units included in 18 detached structures. The subcontractor’s underground work was defective which caused damage to the property’s water line, sewer system, plumbing lines, pavers, etc. The general contractor was liable to the owner for this defective work. Although the general contractor was an additional insured under the subcontractor’s commercial general liability (CGL) policy, the subcontractor’s CGL carrier denied the duty to defend and initiated an insurance coverage lawsuit. Motions for summary judgment were filed.
Read the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Labor Shortages In Construction
December 04, 2023 —
Jason Feld & Chris Bates - Kahana FeldSimilar to other industries, the ongoing labor shortage crisis in the United States is detrimentally impacting construction activities in both the residential and commercial sector. According to the Bureau of Labor Statistics, the turnover rate for the construction industry since 2021 has risen to 56%. And while the national unemployment rate ranges between 0.4% to 7.5%, the unemployment rate for construction is roughly four times the national average (See, Associated Builders and Contractors, Markenstein Advisors Report dated July 28, 2023). 73% of workers preferred to stay in a remote work environment, and another 40% of the global workforce has elected to voluntarily remove themselves from the workplace. (See, 2021 Microsoft Work Index). In particular with the construction industry, employment rates have returned to pre-pandemic levels hovering around 12% unemployment in 2020 to 6% in 2022. (See, Joint Center for Housing Studies at Harvard University, Carlos Martin).
So where did all the workers go? During the height of the 2020 Covid-19 Pandemic and for the next few years, the county experienced what most people are calling “The Great Resignation”. May people took jobs with better pay and better alignment with their values. Approximately 40% stated a new business. Many elected to become stay-at-home parents forgoing a paycheck to raise their families while the other spouse works, especially due to the rising costs of childcare. About 1 in every 4 baby-boomers retired. Others took part-time employment, entered military service or left the workforce due to disability or injury. (See, Bloomberg Businessweek).
Reprinted courtesy of
Jason Feld, Kahana Feld and
Chris Bates, Kahana Feld
Mr. Feld may be contacted at jfeld@kahanafeld.com
Mr. Bates may be contacted at cbates@kahanafeld.com
Read the full story...
Recent Statutory Changes Cap Retainage on Applicable Construction Projects
March 11, 2024 —
Patrick McKnight - The Dispute ResolverRecent reforms to certain state retainage laws have reduced the lawful amount of withholding permitted on construction projects. In theory, retainage allows an owner to mitigate the risk of incomplete or defective work by withholding a certain portion of payment until the construction project is substantially complete. Recent statutory developments in Washington, New York, and Georgia represent significant changes in how much an owner may retain on applicable construction projects in those jurisdictions. The details of each state’s retainage laws vary in many important respects. Most states set caps at 5% or 10%, with important variations depending on the type of project and the amount of progress completed. Some states require retainage to be held in an escrow account, but most do not. Many federal construction projects allow up to 10% retainage, while other federal agencies do not require any retention. See 48 CFR § 52.232-5(e) - Payments Under Fixed-Price Construction Contracts.
The ongoing motivation for retainage reform is typically framed in terms of reducing delays in getting payment to subcontractors who complete their scope of work on time and free from defects.
Read the full story...Reprinted courtesy of
Patrick McKnight, Fox Rothschild LLPMr. McKnight may be contacted at
pmcknight@foxrothschild.com
Missouri Protects Subrogation Rights
April 15, 2024 —
Lian Skaf - The Subrogation StrategistThe point at which an insurance carrier possesses the equitable right of subrogation is an issue on which the states have differed. Some allow carriers to pursue rights of subrogation immediately upon payment and some have taken stricter approaches. Missouri falls into the latter group. By not allowing the carrier the right to file suit against third-party tortfeasors until the insured provides its carrier with an assignment of all its rights, Missouri’s approach has opened the door for challenges to subrogation rights.
In Megown v. Auto Club Fam. Ins. Co., 2024 Mo. App. LEXIS 82, the plaintiff-insureds Michael and Jane Megown (the Megowns) suffered a house fire on February 8, 2016. Their insurance carrier, Auto Club Family Insurance Company (Auto Club) reimbursed the Megowns for their property damage in the amount of $722,433.56. Subsequently, the Megowns sued Auto Club for breach of contract and later amended their complaint to add claims against Tyberius Enterprises, LLC d/b/a Crag Electric (Craig Electric), the third-party tortfeasor, for direct negligence, alleging both property damage and personal injuries. Auto Club intervened in the Megowns’ claim against Craig Electric to protect its interest as subrogee for its property damage payment to the Megowns. Craig Electric settled prior to trial, paying $1,000,000.00 to both the Megowns and Auto Club, to be allocated at a later date. After a bench trial that apportioned the settlement with $722,433.56 paid to Auto Club and $277,566.44 paid to Megowns – and a jury trial awarding no further damages – the Megowns appealed.
Read the full story...Reprinted courtesy of
Lian Skaf, White and Williams LLPMr. Skaf may be contacted at
skafl@whiteandwilliams.com
The Future of Construction Work with Mark Ehrlich
February 19, 2024 —
Aarni Heiskanen - AEC BusinessIn this episode of the AEC Business
podcast, I had the pleasure of speaking with Mark Ehrlich, a veteran of the construction industry from the USA and the author of “The Way We Build: Restoring Dignity to Construction Work.” Our conversation delved into the evolving landscape of construction work and the challenges faced by construction workers today.
Mark shared his extensive background, starting as a carpenter and rising through the ranks to become the head of a 25,000-member union organization. His experience spans decades, and he has authored three books and numerous articles on labor issues.
The historical labor shifts
We discussed the historical shift from a predominantly unionized construction workforce to the current bifurcated system in the US, where union strongholds in the north contrast sharply with the non-union, lower-wage environments in the south and other regions. Mark highlighted the issues of wage theft, declining safety standards, and the exploitation of undocumented workers.
Read the full story...Reprinted courtesy of
Aarni Heiskanen, AEC BusinessMr. Heiskanen may be contacted at
aec-business@aepartners.fi
Stay of Coverage Case Appropriate While Court Determines Arbitrability of Dispute
April 22, 2024 —
Tred R. Eyerly - Insurance Law HawaiiThe Fifth Circuit vacated a discovery order issued by the district court and remanded the case for issuance of a stay while the arbitrability of the coverage dispute was reviewed. Cameron Parish Recreation #6 v. Indian Harbor Ins. Co., et al., 2024 U.S. App. LEXIS 3804 (5th Cir. Feb. 19, 2024).
The plaintiffs purchased surplus lines polices from various insurance companies to provide coverage for commercial properties. The policies included an arbitration provision for resolving any disputes. After plaintiffs were denied coverage for damage to their properties from Hurricane Laura, they sued the insurers. The insurers filed motions to compel arbitration and to stay the case. The district court refused the stay and ordered limited discovery into arbitrability. The insurers appealed.
Read the full story...Reprinted courtesy of
Tred R. Eyerly, Damon Key Leong Kupchak HastertMr. Eyerly may be contacted at
te@hawaiilawyer.com