COLUMBUS OHIO BUILDING CONSULTANT
DIRECTORY AND CAPABILITIES

Ruling Dealing with Constructive Changes, Constructive Suspension, and the Implied Covenant of Good Faith and Fair Dealing

January 22, 2024 — David Adelstein - Florida Construction Legal Updates
A dispute pending in the Armed Services Board of Contract Appeals (ASBCA) dealt with interesting legal issues on a motion to dismiss. See Appeals of McCarthy Hitt-Next NGA West JV, ASBCA No. 63571, 2023 WL 9179193 (ASBCA 2023). The dispute involves a contractor passing through subcontractor claims due to impacts caused by the COVID-19 pandemic and the government’s response to the pandemic. More particularly, the claim centers on the premise that the government “failed to work with [the contractor] in good faith to develop a collaborative and cooperative approach to manage and mitigate the impacts and delays arising from the COVID-19 pandemic.” See Appeals of McCarthy Hitt. The contractor (again, submitting pass through claims from subcontractors) claimed: (a) constructive changes to the contract entitling it to an equitable adjustment under the Changes clause of Federal Acquisition Regulation (F.A.R.) 52.243-4; (b) construction suspensions of the contractor’s work entitling it to an equitable adjustment under the Suspensions of Work clause of F.A.R. 52-242-14; and (c) the government breached the implied covenant of good faith and fair dealing. Each of these legal issues and theories will be discussed below because they are need-to-know legal issues. Keep these legal issues in mind, and the ASBCA’s ruling on the motion to dismiss as its analysis may demonstrate fruitful in other applications. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Breach of Contract Exclusion Bars Coverage for Construction Defect Claim

March 19, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The court determined the policy's breach of contract exclusion precluded coverage for a claim against the general contractor insured for construction defects. Mt. Hawley Ins. Co. v. McAtamncy, 2024 U.S. Dist. LEXIS 497 (N. D. Cal. Jan. 2, 2024). McAtamney, a general contractor dong business as Kilrea Construction, was hired by Jeffrey Horowitz for a home-renovation project. After completion of the project, Horowitz discovered defects in the work. He filed a complaint alleging that Kilrea breached obligations to construct and complete the work in an expeditious and workmanlike manner, free from any faults and defects. He brought claims for breach of contract, breach of implied warranty, negligence, neglignet supervision, and declaratory relief. Kilrea's insurer, Mt. Hawley, agreed to defend, but reserved the right to later deny coverage for any uncovered claims. The breach of contract exclusion provided there was no duty to defend a claim for property damage arising from breach of an express or implied contract or warranty. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

When OSHA Cites You

April 22, 2024 — Michael Metz-Topodas - Construction Executive
With the strong bonds that form among construction project teams, workers looking out for each other helps keep safety foremost in everyone’s mind. But sometimes, even the very best intentions alone can’t prevent an occasional misstep—a forgotten hard hat, a sagging rope line—which can and often does result in an OSHA citation. These regulatory reminders can bring unfortunate consequences: penalties, higher insurance premiums, potential worker injury claims, loss of bidding eligibility, loss of reputation and even public embarrassment, because citations are published on OSHA’s website. Due to citations’ adverse effects, contractors have incentives to minimize them. They can do this by asserting available defenses, because a citation is only an alleged violation, not a confirmed one. But making defenses available begins well before a citation is issued, well before OSHA arrives to a construction site and well before a violation even occurs. Instead, contractors’ ongoing safety programs should incorporate the necessary measures to preserve OSHA citation defenses in three key areas: lack of employee exposure, lack of employer knowledge and impossibility. EMPLOYEE EXPOSURE To sustain a citation against an employer, OSHA must not only identify an applicable standard that the company violated but also show that the violation exposed employees to hazards and risk of injury. Absent evidence of actual exposure, OSHA often makes this showing by asserting that performing job functions necessarily exposes employees to the cited hazard. Reprinted courtesy of Michael Metz-Topodas, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...
Mr. Metz-Topodas may be contacted at michael.metz-topodas@saul.com

---

White and Williams Celebrates 125th Anniversary

March 04, 2024 — White and Williams LLP
White and Williams LLP, a global-reaching law firm headquartered in Philadelphia, PA, is celebrating its 125th Anniversary. Since its founding in 1899, the Firm has grown to two hundred lawyers with offices in Connecticut, Delaware, Maryland, Massachusetts, New Jersey, New York, Rhode Island, and Pennsylvania. “We are proud to celebrate our 125th anniversary. We are grateful to all of our clients for the trust that they place in our firm to handle their important litigation and transactional matters. The partnership we enjoy with our clients is special and a source of great pride to all of us at White and Williams. We are deeply committed to the success of our clients' goals and objectives,” stated Tim Davis, Managing Partner. “We look forward to celebrating this historic milestone with our clients, attorneys, staff and alumni throughout 2024,” added Davis. Read the full story...
Reprinted courtesy of White and Williams LLP

---

Florida's New Pre-Suit Notification Requirement: Retroactive or Prospective Application?

February 05, 2024 — Holly A. Rice - Saxe Doernberger & Vita, P.C.
Florida’s newly formed Sixth District Court of Appeal (“Sixth DCA”) recently certified conflict with Florida’s Fourth District Court of Appeal on the issue of retroactive application of the pre-suit notice requirement contained in Florida Statute §627.70152.1 Earlier this year, the Fourth District Court of Appeal (“Fourth DCA”) held that the pre-suit notice provision applies retroactively, meaning, it applies to all suits filed after July 1, 2021, regardless when the insurance policy was issued.2 The Sixth DCA, in Hughes v. Universal Property & Casualty Insurance Company,3 directly rejected the Fourth DCA’s interpretation and instead found a retroactive application of the pre-suit notice to be unconstitutional under Florida law. Prior to the Fourth DCA’s ruling, most trial courts had found no retroactive application for the pre-suit notice provision.4 In August 2021, shortly after Florida Statutes Section 627.70152 went into effect on July 1, 2021, Rebecca Hughes (“Hughes”) sued Universal Property & Casualty Insurance Company (“Universal Property”) for breach of contract after Universal Property denied her insurance claim. Hughes did not file a pre-suit notice under Section 627.70152. Universal Property moved to dismiss based on Hughes’ failure to file the pre-suit notice, arguing that the pre-suit notice requirement applies to all lawsuits filed after July 1, 2021, even if the claimant’s insurance policy was issued before the statute’s effective date. The trial court agreed with Universal Property and dismissed the lawsuit. Read the full story...
Reprinted courtesy of Holly A. Rice, Saxe Doernberger & Vita, P.C.
Ms. Rice may be contacted at HRice@sdvlaw.com

---

Compliance Doesn’t Pay: Compliance Evidence Inadmissible in Strict Liability Actions

February 05, 2024 — Kyle Rice - The Subrogation Strategist
In Sullivan v. Werner Co., No. 18 EAP 2022, 2023 Pa. LEXIS 1715 (Dec. 22, 2023), the Supreme Court of Pennsylvania (Supreme Court) clarified that in light of its decision in Tincher v. Omega Flex, Inc., 628 Pa. 296 (2014), evidence that a product complied with industry standards is inadmissible in an action involving strict product liability. In Tincher, the Supreme Court overruled prior case law and reaffirmed that Pennsylvania is a Second Restatement Jurisdiction. As stated in Sullivan, discussing Tincher, under the Restatement (Second) of Torts § 402A, a “seller of a product has a duty to provide a product that is free from ‘a defective condition unreasonably dangerous to the consumer or [the consumer’s] property.’ To prove breach of this duty, a ‘plaintiff must prove that a seller (manufacturer or distributor) placed on the market a product in a “defective condition.”” Read the full story...
Reprinted courtesy of Kyle Rice, White and Williams
Mr. Rice may be contacted at ricek@whiteandwilliams.com

---

AI and the Optimization of Construction Projects

February 19, 2024 — Rahul Shah - Construction Executive
Seeking answers on how to construct smarter and greener buildings or improve water efficiency in homes and offices, those who create our buildings and construction projects are entering a new era of learning as they turn their attention to the benefits of artificial intelligence. While human involvement will continue to be paramount, AI has the potential to assist in creating informed decisions, for example by suggesting sustainable, durable materials or cost-effective, but still safe, practices. The possible applications of AI for the construction industry could be transformative across design, procurement, construction, operation and decommissioning. In fact, research suggests designers and contractors are already applying AI and machine learning to manage the volumes of data involved in the design of buildings, the planning of construction projects and the day-to-day operations of sites. Reprinted courtesy of Rahul Shah, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

---

Meet the Forum's In-House Counsel: KATE GOLDEN

February 19, 2024 — Jessica Knox - The Dispute Resolver
Company: Mortenson Email: kate.golden@mortenson.com Website: www.mortenson.com College: University of Iowa (Bachelor of Science in Engineering, 1991) Graduate School: University of Minnesota (Master of Science in Civil Engineering, 1994) Law School: William Mitchell College of Law (now Mitchell | Hamline School of Law) (JD 1999) States Where Company Operates/Does Business: Mortenson is a national builder and developer with 13 regional office locations. Q: Describe your background and the path you took to becoming in-house counsel. A: In high school, I loved math and science, so I attended the University of Iowa College of Engineering and studied civil engineering, with a focus on environmental engineering. To practice environmental engineering at that time, you generally needed a master’s degree, so I attended the University of Minnesota, where my thesis for my degree program was “Organochlorines in Lake Michigan.” I then worked as an environmental engineer for a consulting firm called Montgomery Watson (now MWH) assisting clients with various environmental issues from air permitting to watershed reports to risk assessments of contaminated sites. Read the full story...
Reprinted courtesy of Jessica Knox, Stinson LLP
Ms. Knox may be contacted at jessica.knox@stinson.com

---