Graham & Who May Trigger The Need To Protest
December 23, 2023 —
Hugo Fraga - Ahlers Cressman & Sleight PLLCOn May 30, 2023, the Washington Court of Appeals, Division I, issued a decision that appears to expand a contractor’s obligation with respect to WSDOT notice and claim procedures. In
Graham Contracting, Ltd. v. City of Federal Way, No. 83494-1-I, 2023 WL 3721171 (Wash. Ct. App. May 30, 2023) (Unpublished), the Court held that under the 2016 WSDOT Standard Specifications for Road, Bridge, and Municipal Construction (“Standard Specifications”), a Contractor must protest the actions of not only the “Engineer” but also the actions of any person or organization acting on behalf of the Owner.
This case arises out of a public construction contract in which Graham Contracting Ltd (“Graham”) built a multi-million dollar roadway improvement for the City of Federal Way along a stretch of Pacific Highway. The appeal was from the trial court’s granting of the City’s motion for summary judgment to dismiss claims by Graham for extra time and money due to delays and impacts to Graham’s construction of the Project.
Read the full story...Reprinted courtesy of
Hugo Fraga, Ahlers Cressman & Sleight PLLCMr. Fraga may be contacted at
hugo.fraga@acslawyers.com
NTSB Faults Maintenance, Inspection Oversight for Fern Hollow Bridge Collapse
March 19, 2024 —
Jim Parsons - Engineering News-RecordThe City of Pittsburgh’s failure to act for more than a decade on repeated maintenance and repair recommendations regarding the Fern Hollow Bridge was the probable cause for the structure’s dramatic 2022 collapse, the National Transportation Safety Board (NTSB) said at its Feb. 21, 2024, meeting. The city is the owner of the bridge.
Reprinted courtesy of
Jim Parsons, Engineering News-Record
ENR may be contacted at enr@enr.com
Read the full story...
The Contractor’s Contingency: What Contractors and Construction Managers Need to Know and Be Wary Of
December 04, 2023 —
Skyler L. Santomartino - Peckar & Abramson, P.C.Contractors and construction managers who enter into cost reimbursable contracts subject to a guaranteed maximum price (GMP) are responsible for all project costs exceeding the GMP. For this reason, it is imperative that contractors negotiate and incorporate into the GMP a financial buffer that accounts for the unanticipated project costs that are not reimbursable as change orders or costs of the work. This is where the contractor’s contingency comes into play.[
1]
The contractor’s contingency is a vehicle that allows contractors to mitigate some of the risks inherent in GMP contracts. When drafted properly, a contingency clause allows the contractor and only the contractor to access funds set aside by the owner to address unpredictable or unknown project costs.
Read the full story...Reprinted courtesy of
Skyler L. Santomartino, Peckar & Abramson, P.C.Mr. Santomartino may be contacted at
ssantomartino@pecklaw.com
Environmental Justice Update: The Justice40 Initiative
April 29, 2024 —
Anthony B. Cavender - Gravel2Gavel Construction & Real Estate Law BlogSoon after taking office, President Biden issued Executive Order 14008, entitled, “Tackling the Climate Crisis at Home and Abroad.” This is an unusually long and complex executive order and includes many provisions relating to environmental justice and the plight of “disadvantaged communities” that are overwhelmed by many environmental threats. Section 223 of the Order describes the President’s “Justice40 Initiative,” which is designed to ensure that 40% of Federal benefits flow to disadvantaged communities through an “all of government approach.” There is a recognition that some disadvantaged communities lack the personnel and resources to take advantage of this Initiative, so technical training funds will be made available. The Order establishes new offices throughout the Federal bureaucracy to handle and expedite environmental justice matters.
The Office of Management and Budget (OMB) and the Council on Environmental Quality (CEQ) play a large role in implementing the Initiative by issuing appropriate guidance and assisting the Federal agencies to locate, among the thousands of programs they supervise, suitable programs that will assist disadvantaged communities. At last count, 518 Federal programs administered by 19 distinct Federal agencies could be a good source for the resources needed by disadvantaged communities to cope with air and water pollution and solid waste issues. Direct grants will be made in many cases, and other programs require the community to apply for the funds promised by the Executive Order. In addition, the Order requires participating Federal agencies to assess the value and effectiveness of the benefits bestowed. OMB and the CEQ have issued guidance documents and conducted many meetings with key personnel and members of the disadvantaged communities.
Read the full story...Reprinted courtesy of
Anthony B. Cavender, PillsburyMr. Cavender may be contacted at
anthony.cavender@pillsburylaw.com
Gibbs Giden is Pleased to Announce Four New Partners and Two New Associates
January 08, 2024 —
Gibbs Giden Locher Turner Senet & Wittbrodt, LLPWe take great pleasure in announcing that
Richard Marks and
Kyle Marks have joined the firm. They bring a combined 60 years of real property law experience to Gibbs Giden. Well known Title Insurance and seasoned real estate attorneys they have both served as chair of the Title Insurance Subsection of the Los Angeles County Bar Association and are adjunct professors at Southwestern University School of Law. We are excited to welcome these two exceptional partners and their commitment to representing clients with honesty, integrity, and excellence. You can find them in our firm’s Westlake office.
Talented attorneys
Samantha Riggen and
Christopher Trembley have been named partners. Samantha represents clients in all areas of business and commercial matters with an emphasis on construction litigation on both public and private projects. Christopher’s practice also focuses on construction litigation on behalf of a wide spectrum of industry-stakeholder clients, including suppliers, contractors, and owners. Both work in our firm’s Westlake Village office.
We are also pleased to announce we’ve hired two new associates.
Sarah La Mendola and
Madison Wedderspoon. Sarah has developed an expertise in a wide range of real estate, business, and corporate matters. She received her JD from the University of Pavia, one of the top universities in Italy, in 2012 and her LLM from UCLA in 2015. You can find Sarah in our Westlake Village office. Madison recently graduated from the Boyd School of Law cum laude, is based in our Las Vegas office and works in the areas of business law, contracts, healthcare law, construction, real estate, and common interest community transactional and litigation work.
Read the full story...Reprinted courtesy of
Gibbs Giden
New York Revises Retainage Requirements for Private Construction Contracts: Overview of the “5% Retainage Law”
January 22, 2024 —
Levi W. Barrett, Patrick T. Murray, Skyler L. Santomartino & Mark A. Snyder - Peckar & Abramson, P.C.On November 17, 2023, the State of New York enacted the “5% Retainage Law.” This legislation effectively limits the amount of retainage that can be held from general contractors and subcontractors to no more than 5%. It applies to many but not all construction contracts. In addition, the new law revises late stage billing requirements, enabling contractors to invoice for retainage at substantial completion. Previously, the parties to a construction contract were free to negotiate any retainage amount, limited only by an unspecified “reasonable amount” that would be released as the parties contractually set forth.
Summary
The new law amends Sections 756-a and 756-c of the General Business Law (part of Article 35E of the GBL, known as the “Prompt Pay Act”), and applies to private construction contracts “where the aggregate cost of the construction project, including all labor, services, materials and equipment to be furnished, equals or exceeds one hundred fifty thousand dollars.”
Reprinted courtesy of
Levi W. Barrett, Peckar & Abramson, P.C.,
Patrick T. Murray, Peckar & Abramson, P.C.,
Skyler L. Santomartino, Peckar & Abramson, P.C. and
Mark A. Snyder, Peckar & Abramson, P.C.
Mr. Barrett may be contacted at lbarrett@pecklaw.com
Mr. Murray may be contacted at pmurray@pecklaw.com
Mr. Santomartino may be contacted at ssantomartino@pecklaw.com
Mr. Snyder may be contacted at msnyder@pecklaw.com
Read the full story...
The (Jurisdictional) Rebranding of The CDA’s Sum Certain Requirement
April 15, 2024 —
Jordan A. Hutcheson and Stephanie Rolfsness - Watt TiederThe Contract Disputes Act (the “CDA”), 41 U.S.C.A. §§ 7101 et seq., which has provided the statutory framework for resolution of most contract disputes between the federal government and its contractors since 1978, has recently been the subject of changes in judicial interpretation, despite no corresponding statutory changes. The CDA’s implementing provisions in the Federal Acquisition Regulations (FAR), require that contractors submit a claim to the government in the form of written demand to a contracting officer requesting a final decision and seeking the payment of money in a sum certain prior to pursuing resolution via board or court. However, with respect to the sum certain requirement, the United States Court of Appeals for the Federal Circuit issued an opinion in late 2023 determining that this requirement “should not be given the jurisdictional brand” as it has categorically received in the past. Rather, the court concluded that the sum certain requirement is merely an element of a claim for relief under the CDA that a contractor must satisfy to recover. This rebranding does not debase the sum certain requirement, but it does indicate a renewed focus on what constitutes “jurisdictional” in government contracts litigation.
Reprinted courtesy of
Jordan A. Hutcheson, Watt Tieder and
Stephanie Rolfsness, Watt Tieder
Ms. Hutcheson may be contacted at jhutcheson@watttieder.com
Ms. Rolfsness may be contacted at srolfsness@watttieder.com
Read the full story...
Top 10 OSHA Violations For The Construction Industry In 2023
February 26, 2024 —
Dominic Donato & Jeff Miragliotta - Kahana FeldEvery year, the Occupational Safety and Health Administration (OSHA) publishes their top violations in the construction industry. And typically, the most common violations are consistent year after year. What separates 2023 is the number of citations involving Fall Protection, Scaffolding, Ladders, and the failure to use personal protective equipment (PPE) or other life safety equipment (LSE). The following is the list of the Top Ten OSHA violations for 2023:
(10) Toxic and Hazardous Substances. There were 382 citations issued for “hazardous communication” and improper warnings issued to construction employees.
(9) Excavations. There were 395 citations issued for failure to provide proper and specific excavation requirements and instructions.
(8) Scaffolding – Aerial Lifts. There were 481 citations issued for improper lifting equipment and supports for building scaffolding.
Reprinted courtesy of
Dominic Donato, Kahana Feld and
Jeff Miragliotta, Kahana Feld
Mr. Donato may be contacted at ddonato@kahanafeld.com
Mr. Miragliotta may be contacted at jmiragliotta@kahanafeld.com
Read the full story...