Ruling Dealing with Constructive Changes, Constructive Suspension, and the Implied Covenant of Good Faith and Fair Dealing
January 22, 2024 —
David Adelstein - Florida Construction Legal UpdatesA dispute pending in the Armed Services Board of Contract Appeals (ASBCA) dealt with interesting legal issues on a motion to dismiss. See Appeals of McCarthy Hitt-Next NGA West JV, ASBCA No. 63571, 2023 WL 9179193 (ASBCA 2023). The dispute involves a contractor passing through subcontractor claims due to impacts caused by the COVID-19 pandemic and the government’s response to the pandemic. More particularly, the claim centers on the premise that the government “failed to work with [the contractor] in good faith to develop a collaborative and cooperative approach to manage and mitigate the impacts and delays arising from the COVID-19 pandemic.” See Appeals of McCarthy Hitt.
The contractor (again, submitting pass through claims from subcontractors) claimed: (a) constructive changes to the contract entitling it to an equitable adjustment under the Changes clause of Federal Acquisition Regulation (F.A.R.) 52.243-4; (b) construction suspensions of the contractor’s work entitling it to an equitable adjustment under the Suspensions of Work clause of F.A.R. 52-242-14; and (c) the government breached the implied covenant of good faith and fair dealing. Each of these legal issues and theories will be discussed below because they are need-to-know legal issues. Keep these legal issues in mind, and the ASBCA’s ruling on the motion to dismiss as its analysis may demonstrate fruitful in other applications.
Read the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Graham & Who May Trigger The Need To Protest
December 23, 2023 —
Hugo Fraga - Ahlers Cressman & Sleight PLLCOn May 30, 2023, the Washington Court of Appeals, Division I, issued a decision that appears to expand a contractor’s obligation with respect to WSDOT notice and claim procedures. In
Graham Contracting, Ltd. v. City of Federal Way, No. 83494-1-I, 2023 WL 3721171 (Wash. Ct. App. May 30, 2023) (Unpublished), the Court held that under the 2016 WSDOT Standard Specifications for Road, Bridge, and Municipal Construction (“Standard Specifications”), a Contractor must protest the actions of not only the “Engineer” but also the actions of any person or organization acting on behalf of the Owner.
This case arises out of a public construction contract in which Graham Contracting Ltd (“Graham”) built a multi-million dollar roadway improvement for the City of Federal Way along a stretch of Pacific Highway. The appeal was from the trial court’s granting of the City’s motion for summary judgment to dismiss claims by Graham for extra time and money due to delays and impacts to Graham’s construction of the Project.
Read the full story...Reprinted courtesy of
Hugo Fraga, Ahlers Cressman & Sleight PLLCMr. Fraga may be contacted at
hugo.fraga@acslawyers.com
Catching Killer Clauses in Contract Negotiations
January 29, 2024 —
James T. Dixon - Construction ExecutiveRisk-management personnel who are in the business of reviewing and negotiating construction contracts have some simple tools at their disposal to make sure their edits are addressing all of the killer risk-shifting clauses in those contracts. One of those is the index to that document. But not all authors of construction contract documents are kind enough to include an exhaustive index in their form agreements.
One of the most popular sets of general conditions, the A201 General Conditions published by the American Institute of Architects, includes one that is fairly comprehensive. It identifies the six terms that include a reference to indemnification, for example. On the other end of the spectrum are the innumerable custom forms created by public and private project owners, and these rarely have an index.
Even more powerful than an index is the search or find functions that are available in word processing applications and now in Adobe, the publisher of documents in portable document format, more commonly known as PDF. But with PDF documents, one must be careful to make sure the document under review is in fact searchable. Because every letter counts, it is important to have full confidence in the integrity of the search.
Reprinted courtesy of
James T. Dixon, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the full story...
The (Jurisdictional) Rebranding of The CDA’s Sum Certain Requirement
April 15, 2024 —
Jordan A. Hutcheson and Stephanie Rolfsness - Watt TiederThe Contract Disputes Act (the “CDA”), 41 U.S.C.A. §§ 7101 et seq., which has provided the statutory framework for resolution of most contract disputes between the federal government and its contractors since 1978, has recently been the subject of changes in judicial interpretation, despite no corresponding statutory changes. The CDA’s implementing provisions in the Federal Acquisition Regulations (FAR), require that contractors submit a claim to the government in the form of written demand to a contracting officer requesting a final decision and seeking the payment of money in a sum certain prior to pursuing resolution via board or court. However, with respect to the sum certain requirement, the United States Court of Appeals for the Federal Circuit issued an opinion in late 2023 determining that this requirement “should not be given the jurisdictional brand” as it has categorically received in the past. Rather, the court concluded that the sum certain requirement is merely an element of a claim for relief under the CDA that a contractor must satisfy to recover. This rebranding does not debase the sum certain requirement, but it does indicate a renewed focus on what constitutes “jurisdictional” in government contracts litigation.
Reprinted courtesy of
Jordan A. Hutcheson, Watt Tieder and
Stephanie Rolfsness, Watt Tieder
Ms. Hutcheson may be contacted at jhutcheson@watttieder.com
Ms. Rolfsness may be contacted at srolfsness@watttieder.com
Read the full story...
Just How Climate-Friendly Are Timber Buildings? It’s Complicated
February 12, 2024 —
Eric Roston - BloombergThis article is part of the Bloomberg Green series Timber Town, which looks at the global rise of timber as a low-carbon building material.
The number of people living in urban areas around the world
will swell by upwards of 2 billion over the next three decades. Many of those people will need new homes. But building those with conventional materials would unleash a gusher of carbon dioxide: Concrete, steel, glass and bricks for construction make up a combined
9% of global CO2 emissions, according to research by the United Nations Environment Program.
Enter engineered wood, a seemingly no-brainer solution.
Mass timber is not the typical lumber that has structured single-family houses in North America for decades. The wood components are strong enough to hold up an office tower or apartment block, and building with them is thought to emit much less CO2 than using standard materials. And since wood is about 50% carbon, the material itself even stores a little carbon, to boot.
Read the full story...Reprinted courtesy of
Eric Roston, Bloomberg
See the Stories That Drew the Most Readers to ENR.com in 2023
January 16, 2024 —
C.J. Schexnayder - Engineering News-RecordAs construction's very busy and eventful year nears its close and the sector awaits many more ups and downs in 2024, ENR offers a look back at the Top 20 news stories that most caught readers' attention across a broad market spectrum—from the construction start of the long-awaited $16 billion New York-New Jersey rail tunnel rebuild and winners shortlisted for the first $7 billion in U.S. government funds for developing clean-energy hydrogen hubs to the still unfolding legal battle over Las Vegas Sphere project complexities and why a Texas jury awarded $860 million in a fatal Texas crane collapse verdict.
Reprinted courtesy of
C.J. Schexnayder, Engineering News-Record
Mr. Schexnayder may be contacted at schexnayderc@enr.com
Read the full story...
Compliance with Contractual and Jurisdictional Pre-Suit Requirements is Essential to Maximizing Recovery
November 27, 2023 —
Michael S. Levine, Geoffrey B. Fehling & Charlotte Leszinske - Hunton Insurance Recovery BlogTimely notice is an important first step in a successful insurance recovery. But insurance policies are not always straightforward in identifying how, when, and to whom notice must be provided. Some states may also impose additional procedural hurdles, including requiring policyholders to contact their insurers before filing suit (the idea behind this requirement is that it may avoid litigation). Failing to comply with pre-suit requirements can hurt the policyholder’s recovery, as illustrated in a recent decision from the Northern District of Texas.
In NewcrestImage Holdings, LLC v. The Travelers Lloyds Insurance Company, No. 2:23-cv-039-BR (N.D. Tex. Oct. 17, 2023), the court considered whether NewcrestImage had forfeited its right to recover attorneys’ fees by failing to give Travelers pre-suit notice. NewcrestImage had filed suit against Travelers to obtain coverage for damage to its hotel property arising out of Winter Storm Uri. In its answer, Travelers asserted that NewcrestImage failed to provide the insurer with pre-suit notice as required under the Texas Insurance Code, and that if NewcrestImage successfully proved it was entitled to coverage, NewcrestImage’s failure to provide pre-suit notice precluded it from recovering attorneys’ fees. Travelers later moved to strike the claim for attorneys’ fees on that basis.
Reprinted courtesy of
Michael S. Levine, Hunton Andrews Kurth,
Geoffrey B. Fehling, Hunton Andrews Kurth and
Charlotte Leszinske, Hunton Andrews Kurth
Mr. Levine may be contacted at mlevine@HuntonAK.com
Mr. Fehling may be contacted at gfehling@HuntonAK.com
Ms. Leszinske may be contacted at cleszinske@HuntonAK.com
Read the full story...
Don’t Fall in Trap of Buying the Cheapest Insurance Policy as it May be Bad for Your Business Risks and Needs
March 25, 2024 —
David Adelstein - Florida Construction Legal UpdatesDon’t fall in the trap of buying the cheapest insurance policy. It will come and bite you in the butt big time! Consult with an insurance broker that understands construction and, importantly, your specific industry, to provide you coverage within your industry. Otherwise, you’ll be paying for a policy that may (i) not be a good policy, and (ii) may provide you minimal to no value for your industry’s RISKS and NEEDS when factoring in exclusions. When procuring insurance, think of the old adage “penny wise and pound foolish,” and don’t make decisions that fit within this adage!
The recent decision in Nautilus Ins. Co. v. Pinnacle Engineering & Development, Inc., 2024 WL 940527 (S.D. Fla. 2024) serves as an example. Here, a subcontractor was hired by a general contractor to perform underground utility work for a townhome development which consisted of 57 townhome units included in 18 detached structures. The subcontractor’s u
California Booms With FivePoint New Schools: Real EstateUsing Lien and Bond Claims to Secure Project PaymentsMore Broad-Based Expansion for Construction Industry Expected in 2015Performance Bonds: Follow the Letter of the Bond and Keep The Surety InformedWhat is a Civil Dispute?Best Lawyers Recognizes Hundreds of Lewis Brisbois Attorneys, Honors Four Partners as ‘Lawyers of the Year’NYC Condo Skyscraper's Builder Wins
Will Millennial’s Desire for Efficient Spaces Kill the McMansion?
Construction Slow to Begin in Superstorm Sandy Cases
In Midst of Construction Defect Lawsuit, City Center Seeks Refinancing
Traub Lieberman Attorneys Win Motion for Judgment on the Pleadings In Favor of Insurer
NYC Building Explosion Kills Two After Neighbor Reports Gas Leak
Force Majeure Under the Coronavirus (COVID-19) Pandemic
Are We Headed for a Work Shortage?
Rise in Single-Family Construction Anticipated in Michigan
New Certification Requirements for Veteran-Owned Small Business Concerns and Service-Disabled Veteran-owned Small Business Concerns Seeking Public Procurement Contracts
Colorado SB 15-177 UPDATE: Senate Business, Labor, & Technology Committee Refers Construction Defect Reform Bill to Full Senate
Condominium Construction Defect Resolution in the District of Columbia
SDNY Vacates Arbitration Award for Party-Arbitrator’s Nondisclosures
New Spending Measure Has Big Potential Infrastructure Boost
Court Orders City to Pay for Sewer Backups
Red Wings Owner, Needing Hockey-Arena Neighborhood, Builds One
Insurer Liable for Bad Faith Despite Actions of Insured Contributing to Excess Judgment
2022 California Construction Law Update
Federal District Court Finds Coverage Barred Because of Lack of Allegations of Damage During the Policy Period and Because of Late Notice
Construction Contracts and The Uniform Commercial Code: When Does it Apply and Understanding the Pre-Dominant Factor Test
Falls Requiring Time Off from Work are Increasing
Forget the Apple Watch. Apple’s Next Biggest Thing Isn’t for Sale
Know What You’ve Built: An Interview with Timo Makkonen of Congrid
Get Construction Defects in Writing
If I Released My California Mechanics Lien, Can I File a New Mechanics Lien on the Same Project? Will the New Mechanics Lien be Enforceable?
Tishman Construction Admits Cheating Trade Center Clients
Beyond the COI: The Importance of an Owner's or Facilities Manager's Downstream Insurance Review Program
A Deep Dive Into an Undervalued Urban Marvel
Determining Duty to Defend in Wisconsin Does Not Include Extrinsic Evidence
The G2G Year-End Roundup (2022)
The Pandemic, Proposed Federal Privacy Regulation and the CCPA
Fifth Circuit Certifies Eight-Corners Duty to Defend Issue to Texas Supreme Court
Cameron Kalunian to Speak at Casualty Construction Defect Seminar
The Devil is in the Details: The Texas Construction Trust Fund Pitfalls Residential Remodelers (and General Contractors) Should Avoid
Construction Law Job Opps and How to Create Them
If You Don’t Like the PPP Now, Wait a Few Minutes…Major Changes to PPP Loan Program as Congress Passes Payroll Protection Program Flexibility Act
NIST Florida Condo Collapse Probe Develops Dozens of Hypotheses
Plaintiff’s Mere Presence in Area Where Asbestos is Present Insufficient to Establish Bystander Exposure
The Biggest Change to the Mechanics Lien Law Since 1963
Home Construction Slows in Las Vegas
Louisiana Court Applies Manifestation Trigger to Affirm Denial of Coverage
California Supreme Court Declares that Exclusionary Rule for Failing to Comply with Expert Witness Disclosures Applies at the Summary Judgment Stage
Breaking The Ice: A Policyholder's Guide to Insurance Coverage for Texas Winter Storm Uri Claims
Best Practices for ESI Collection in Construction Litigation
Updated 3/13/20: Coronavirus is Here: What Does That Mean for Your Project and Your Business?
The California Privacy Rights Act Passed – Now What?
Insurer Must Cover Portions of Arbitration Award
Top 10 OSHA Violations For The Construction Industry In 2023
Don MacGregor of Bert L. Howe & Associates Awarded Silver Star Award at WCC Construction Defect Seminar
There’s an Unusual Thing Happening in the Housing Market
IRMI Expert Commentary: Managing Insurance Coverage from Multiple Insurers