Fairfield Connecticut Building Consultant Directory

No Damages for Delay May Not Be Enforceable in Virginia

January 08, 2024 — Christopher G. Hill - Construction Law Musings
Anyone who reads Construction Law Musings with any regularity (thank you by the way) knows that the contract is king in most instances here in Virginia. Any commercial construction subcontractor in Virginia is likely also very familiar with so-called “no damages for delay” clauses in construction contracts. These clauses essentially state that a subcontractor’s only remedy for a delay caused by any factor beyond its control (including the fault of the general contractor), after proper notice to the general contractor, is an extension of time to complete the work. However, in 2015 the Virginia General Assembly passed a change in the law that precluded the diminishment of any right to claims for demonstrated additional costs prior to payment. This left open the question as to which types of “diminishment” would be barred by the statute. The recent case out of the Eastern District of Virginia federal court, Strata Solar LLC v. Fall Line Construction LLC, added a bit of clarity. Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Traub Lieberman Partner Michael K. Kiernan and Associate Brandon Christian Obtain Dismissal with Prejudice in Favor of Defendant

November 27, 2023 — Michael K. Kiernan & Brandon Christian - Traub Lieberman
In a 14-count breach of contract action brought in the Fifteenth Judicial Circuit in Palm Beach County, Florida, Partner Michael K. Kiernan and Associate Brandon Christian obtained dismissal with prejudice in favor of Defendant St. Joseph’s Episcopal Church of Boynton Beach, Florida (“Church”). Plaintiffs, St. Joseph’s Episcopal School (“School”) and its benefactor, William Swaney, filed suit to enforce an alleged 99-year oral lease agreement which Swaney asserted had been made to him by a prior rector of the Church in exchange for his contributions to the School. Plaintiffs also sought emergency injunctive relief to allow the School to continue to operate on Church property. The Church maintained in part that the only lease in effect was a written lease, approved by the Church Vestry and the Diocese of Southeast Florida, and which the Church Vestry unanimously voted not to renew in 2022. Reprinted courtesy of Michael K. Kiernan, Traub Lieberman and Brandon Christian, Traub Lieberman Mr. Kiernan may be contacted at mkiernan@tlsslaw.com Mr. Christian may be contacted at bchristian@tlsslaw.com Read the full story...

Insurer's Motion for Judgment on the Pleadings for Construction Defect Claim Rejected

January 22, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The magistrate judge recommended that the insurer's motion for judgment on the pleadings be denied in a case involving coverage for the insured subcontractor's alleged faulty workmanship. Evanston Ins. Co. v. Sonny Glasbrenner, Inc., 2023 U.S. Dist. LEXIS 190019 (M.D. Fla. Oct. 20, 2023). Cone & Graham (C&G), the general contractor, subcontracted with Sonny Glasbrenner, Inc. (SGI) to work on the project. The project involved the rehabilitation of a bridge due to deterioration of the existing concrete bridge deck by adding additional cross bracing to further stiffen the steel girders and using special lightweight concrete. C&G contracted SGH to demolish the existing concrete bridge deck. SGI completed the work. Thereafter, C&G made a demand to SGI for alleged damaged caused by SGI's work. C&G alleged that SGI was negligent in performing the demolition work, causing substantial damage to the existing bridge girders. C&G sued SGI. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

The Top 3 Trends That Will Impact the Construction Industry in 2024

December 04, 2023 — The Hartford Staff - The Hartford Insights
As more than 40% of the current U.S. construction workforce will retire in the next decade, industry leaders need to equip themselves with the necessary resources to combat the shifting work environment.1 “Trends in the construction industry will fluctuate in the coming years, which can lead to additional risks for industry leaders. It will be important to think about how they can address any potential risk factors. A lot of leaders have been increasing their planning efforts and looking into technology solutions to combat the ongoing labor shortage,” said David DeSilva, head of construction at The Hartford. Here, he outlines the top three top trends for business leaders to watch in 2024. 1. Ongoing Labor Shortages Construction is an industry that traditionally has a high labor turnover rate, which means companies needs to hire more frequently. This only increases during labor shortages. The construction workforce is up against several factors, including an aging workforce and recruitment struggles. Read the full story...
Reprinted courtesy of The Hartford Staff, The Hartford Insights

Contract Should Have Clear and Definite Terms to Avoid a Patent Ambiguity

December 11, 2023 — David Adelstein - Florida Construction Legal Updates
If you need more of a reason to have contracts with clear and definite terms, this case is it. This case exemplifies what can happen if the contract, not only does not have clear and definite terms, but contains a patent ambiguity. The contract will be deemed unenforceable which will make one of the contracting parties very unhappy! In Bowein v. Sherman, 48 Fla.L.Weekly D2208a (Fla. 6th DCA 2023), the buyer and seller entered into a real estate transaction. The transaction was for $2 Million. The purchase-and-sale agreement included the address and legal description of a parcel to be sold. However, there was a section in the agreement called “Other Terms and Conditions” which identified that the offer was actually for four properties that were being sold by the seller. When it came to closing time, the seller refused to close because the seller disputed that the $2 Million purchase price was for all four of his properties. The buyer sued the seller for specific performance to force the sale which the trial court agreed in favor of the buyer. However, the appellate court did not. First, the appellate court held that “[t]he equitable remedy of specific performance may be granted only where the parties have actually entered into a definite and certain agreement.” Bowein, supra (quotation and citation omitted). Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Federal Court Reiterates Broad Duty to Defend in Additional Insured Cases

April 22, 2024 — Craig Rokuson - Traub Lieberman
In the recent case of Travelers Indem. Co. of Am. v. Accredited Sur. & Cas. Co., No. 21-CV-7189 (FB) (JRC), 2024 U.S. Dist. LEXIS 44634 (E.D.N.Y. Mar. 13, 2024), the Federal District Court for the Eastern District of New York had occasion to consider an additional insured tender on behalf of a prime contractor, Archstone, to a subcontractor, Topline, who was named as a direct defendant in a New York labor law case. Even though Topline’s carrier put forth evidence that Topline was not negligent, the court held, under New York’s broad duty to defend, that Topline’s carrier owed a duty to defend the prime contractor. Initially, the court was satisfied that a purchase order, signed only by Topline and not Archstone, was binding on Topline. That purchase order specified that Topline agreed to name Archstone as an additional insured. With respect to the duty to defend, the court found that it was enough that the underlying plaintiff alleged that all defendants, including Topline, were negligent in permitting a ladder that plaintiff was on to remain in a defective condition and in failing to foresee the existence of a hazard from the condition of the subject ladder. Read the full story...
Reprinted courtesy of Craig Rokuson, Traub Lieberman
Mr. Rokuson may be contacted at crokuson@tlsslaw.com

Arizona Is Smart About Water. It Should Stay That Way.

February 19, 2024 — Mark Gongloff - Bloomberg
You really have to hand it to Arizona: Even as its population has doubled and it has suffered through a decades long megadrought, the state uses less water today than it did 40 years ago. This success story is the result of what may be the smartest, most conservative approach to water in the country. But homebuilders want to scrap some key elements of this careful system. It’s a bad idea, especially as the climate changes, making the state’s water supply less reliable. And it’s a cautionary tale for the rest of us as we try to adapt to a warming world. In 1980, alarmed at watching its precious groundwater disappear amid rapid development, Arizona passed the Groundwater Management Act. The law established the Arizona Department of Water Resources, set up water-management zones around cities and required new housing developments to prove they had access to 100 years’ worth of clean water, among other things. Read the full story...
Reprinted courtesy of Mark Gongloff, Bloomberg

A Look at Trending Legislative Changes Impacting Workers' Comp

February 26, 2024 — Rosanna Shamash - Construction Executive
The tides are shifting in the construction industry when it comes to legal matters—and business owners could feel the brunt of it. Recent legislative changes in the state of New York could signal how workers’ compensation cases move forward across the country and impact business owners in the space. Arguably, New York has historically laid the groundwork for workers’ compensation law in numerous other states. Now, we’re seeing a clear shift in favor of workers with some of the recent legislative changes. Owners, operators and executives in the construction space have increasingly found themselves facing costly claims that in years prior carried a smaller dollar value and were largely viewed as inconsequential. So, what’s the best way for business owners in the construction industry to protect their businesses for the future? Start by gaining a basic understanding of changes in the legal landscape, by securing defense attorneys who know the construction space and by taking steps to protect your business before an incident happens. Reprinted courtesy of Rosanna Shamash, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

FAIRFIELD CONNECTICUT BUILDING CONSULTANT DIRECTORY AND CAPABILITIES